Transform Your Space with Expert Interior Design

×

Privacy Policy

Effective Date: January 1, 2026

Information We Collect

We collect information you provide directly to us, such as when you contact us for interior design services, request a consultation, or subscribe to our updates. This may include your name, email address, phone number, project details, and design preferences.

How We Use Your Information

We use the information we collect to provide interior design services, respond to your inquiries, send you updates about our services, and improve our business operations. We may also use your information to personalize your experience and provide relevant design recommendations.

Information Sharing

We do not sell, trade, or otherwise transfer your personal information to third parties without your consent, except as described in this policy. We may share information with trusted partners who assist us in operating our business, provided they agree to keep your information confidential.

Data Security

We implement appropriate security measures to protect your personal information against unauthorized access, alteration, disclosure, or destruction. However, no method of transmission over the internet is 100% secure.

Contact Us

If you have questions about this Privacy Policy, please contact us at [email protected] or call +1 602-473-8529.

×

Terms of Service

Effective Date: January 1, 2026

Acceptance of Terms

By accessing and using Detail Driven Interiors services, you accept and agree to be bound by the terms and provision of this agreement. If you do not agree to abide by the above, please do not use this service.

Service Description

Detail Driven Interiors provides professional interior design services including but not limited to residential design, commercial design, color consultation, space planning, furniture selection, and lighting design.

Client Responsibilities

Clients are responsible for providing accurate information about their project requirements, budget constraints, and timeline expectations. Clients must provide reasonable access to the project site and make timely decisions when requested.

Payment Terms

Payment terms will be specified in individual service agreements. Generally, a deposit is required to begin work, with remaining payments due according to project milestones or completion.

Intellectual Property

All design concepts, plans, and materials created by Detail Driven Interiors remain our intellectual property until full payment is received. Upon full payment, clients receive usage rights for their specific project.

Limitation of Liability

Detail Driven Interiors liability is limited to the amount paid for services. We are not responsible for delays caused by factors beyond our control, including but not limited to supplier delays, permit issues, or client-requested changes.

Contact Information

For questions regarding these terms, contact us at [email protected] or +1 602-473-8529.

×

Disclaimer

Last Updated: January 1, 2026

Professional Services Disclaimer

Detail Driven Interiors provides interior design services based on professional experience and industry standards. While we strive for excellence in all projects, design preferences are subjective, and results may vary based on individual tastes and expectations.

Third-Party Products and Services

We may recommend third-party contractors, suppliers, or products. While we make recommendations based on our professional judgment, we are not responsible for the quality, performance, or warranty of third-party products or services.

Project Timelines

Project timelines are estimates based on typical project flows. Actual completion times may vary due to factors including but not limited to material availability, permit processing, weather conditions, and client-requested changes.

Budget Estimates

Cost estimates are provided in good faith based on current market conditions and project specifications. Final costs may vary due to material price fluctuations, scope changes, or unforeseen project requirements.

Design Suitability

While we consider structural and safety factors in our designs, clients are responsible for ensuring all modifications comply with local building codes and regulations. We recommend consulting with licensed contractors and engineers as needed.

No Warranty

Our design services are provided "as is" without warranty of any kind. We disclaim all warranties, express or implied, including but not limited to merchantability and fitness for a particular purpose.

Contact Us

If you have questions about this disclaimer, please contact us at [email protected] or +1 602-473-8529.